Navigation

Superior Interiors

E-Mail: si2006@comcast.net

425-670-1442

24315 89th PL W

Edmonds, WA 98026

EMAIL:  SI2006@COMCAST.NET

LOCATED IN SOUTH SNOHOMISH COUNTY

 

Superior Interiors

24315 89th PI W
Edmonds, Washington 98026

Phone: (425) 670-1442

Cell: (206) 369-4606

Fax: (425) 670-1614

E-mail: si2006@comcast.net

 

Contract Conditions

SUPERIOR INTERIORS CONTRACT CONDITIONS
 
1. CHANGES IN THE WORK:  The Customer may request changes or modifications in the scope of work. This is known as extra work. These requests may be agreed upon orally; email, or in writing. If agreed upon in writing, such changes or modifications shall be identified and agreed upon in a written change order form prepared by
Superior Interiors. Unless otherwise agreed in writing, all extra work performed by Superior Interiors shall be billed at the rate of $55.00 per hour for all labor. The Customer agrees to pay the wholesale price on all material according to Moore Publications, plus 20% for handling. All special order goods & cabinets are not refundable. All costs of change orders are due and payable ten days from date of invoice.

 

2. DELAYS. Should the Customer directly or indirectly cause delays or interruptions in the performance of Superior Interiors work, the Customer agrees to compensate for its loss of time on the project in accordance with paragraph 1. Contractor not liable for delays on delivery of special order materials, cabinets; subcontractors' delays; work completion due to weather conditions.

 

3. NOTICE TO PROCEED. Superior Interiors shall proceed promptly upon receipt of notice to proceed from the Customer, credit confirmation and signed contract. All work shall be completed in a timely manner. All custom cabinet orders confirmed by client signature are non refundable.

 

4. SCHEDULING. It is the responsibility of the Customer to schedule Superior Interiors work under this contract. If Superior Interiors arrives at the job site to find it not ready, the Customer agrees to pay for the expense of a non-productive trip. Any additional trips required due to Customer delay or preparation will be charged pursuant to paragraph 1.  $115.00 minimum trip charge. In the event that client cancels signed contract; he shall forfeit 20% of contact amount to contractor.

 

5. DAMAGE OR INJURY TO PERSONS OR PROPERTY. Superior Interiors is not responsible for any damage to the premises resulting from frozen or damaged pipes, after installation, and is not responsible for damage to fixtures or any products, after installation.

 

6. BUILDING CODES. All work shall be as per code. Non permit jobs-Client is solely responsible for any fines/citations levied against contractor. Superior Interiors shall complete its work according to the approved set of drawings and specifications. If approved drawings have been issued by a jurisdictional building department,
Superior Interiors may rely upon those as conforming to all applicable regulations. In the event of required changes by the jurisdictional or governmental departments, the owner shall be notified of such including the cost adjustments as per paragraph 1.

 

7. WARRANTY. Superior Interiors warrants that all labor, materials and taxes will be paid for, and there will be no potential lien claimants upon the completion of the work. Superior Interiors warrants that all work will be performed in a commercially reasonable manner and that there are no defects in materials or workmanship. This warranty is for a period of 2 (two) Year from the date of the final contract invoice. This warranty shall be void if a person or firm other than Superior Interiors performs or redoes any work identified within the scope of the work of this contract.

 

8. ATTORNEY’S FEES.  In the event a dispute or lawsuit arises and one or both parties seek and receive the assistance of legal counsel, the prevailing party shall be paid his or her actual attorneys fees and costs by the non-prevailing party. There shall be one prevailing party which shall be the one party in whose favor a net monetary judgment is awarded, after all offsets, claims, counterclaims, allowances, etc. Have been resolved, and regardless of any previous offers between the parties, regardless of whether both parties prevailed on one or more issues. As used herein “ actual attorneys’ fees” shall be deemed to mean the full and actual cost of any legal services actually performed in connection with the matters involved, calculated on the usual fees charged by the attorneys performing such services; and shall not be limited to “ reasonable attorneys fees” as defined by any statute, case or rule of court. This clause shall supersede all Washington statutes, dealing with awards of costs or attorneys fees. The court shall determine the net monetary award or judgment without regard to any payments made or offered once the suit has been commenced.

 

9. CONFLICT WITH OTHER SUBCONTRACTS. In the event that Superior Interiors. Signs any other subcontract for performance of the work identified by this contract, the terms and provisions of this contract shall control and supersede the terms of any other subcontract wherever they conflict or are inconsistent.

10. EXCLUSIONS. Unless stated below, this contract covers only those items described on the front of the contract. Or by written change order, there are no exceptions.

 

11. CORRECTION OF COMPLETION OF WORK. Superior Interiors shall have the irrevocable right to perform all corrective or pick-up work identified by the Customer unless Superior Interiors declines to do so following receipt of a specific list and a reasonable period of time within which to perform the work. The Customer shall not contract with any alternative contractor for the performance of any of the above. Should the Customer occupy the space, or contract outside of this contract he/she then agrees to accept all work “as is’ and thereby waives any and all claims, of whatever nature, against Superior Interiors, including warranty claims.

 

12. RETAINING OR HOLDING. The Customer shall retain no greater percentage from
Superior Interiors as per work performed. Said retainer becomes due and payable upon completion and acceptance of work. 18% APR compound interest will accrue on unpaid balance; Customer agrees to pay all expenses for Attorney’s fees; Court and Collection fees.

 

13. NON-PERMIT JOBS. The Customer assumes all liability for permits, any fines/citations and laws pertaining to said construction. Contractors shall be held blameless.

 

14. “Any controversy or claim arising out of or relating to this contract or any breach thereof, may be settled in accordance with the arbitration tribunal of the Better Business Bureau or Civil Court.”

 

15. The contractor is registered with the State of Washington, registration number SUPERI*077DW, as a general contractor and has posted with the state a bond for the purpose of satisfying claims against the contractor for negligent or improper work or breach of contract. Contractor is required to provide you with further information about lien release documents if you request it. General information is also available from the Department of Labor & Industries, at 1-800-647-0892.
Http://www.superiorinteriors.cc